黑洞社区

鈥滷air allocation of risk鈥� is a mantra trotted out in contract negotiations for almost every construction contract. Most bodies that produce standard forms will say that their standard forms, if left unamended, will achieve just that.

Another new release of standard forms, this time from FIDIC, should hit the market next month (see my 黑洞社区 article, 27 January). These will be the construction only, design and build (and plant), and turnkey forms (the red, yellow and silver books). One of the changes in these forms concerns the approach to risk allocation between employer and contractor.  

Before looking at this change of approach, it is useful to stand back and consider what is meant by risk allocation. Where a contract allocates a risk to a party, that party funds the consequences of that risk occurring. So, if a risk is allocated to the contractor, the contractor meets any cost consequences of this should it occur, without additional payment from the employer. If the risk allocated to the employer occurs, the employer must fund the cost from its own resources and not look to the contractor.

Contracts specifically allocate many risks through the contract conditions and also sometimes through risk matrices drafted by the parties and included in the contract. This should not include the risk register required under NEC3, which is not about allocating legal liability for risks. NEC4 has changed the terminology to deter people from using it in this way by renaming it an 鈥渆arly warning register鈥�.

Specific risks allocated by FIDIC, for example, include: errors in employer鈥檚 requirements; right to access the site; setting out; unforeseen physical conditions; delays caused by authorities; changes in law; and interference with tests on completion.

But what about those risks that are not expressly allocated? How do you determine who bears these? Where the contract is silent on who bears the risk of particular events, can this be deduced from the other provisions within the contract?

If not, a useful approach in those circumstances is to assume the risk lies where it falls. For example, take the risk of adverse weather (however that may be defined) increasing the contractor鈥檚 cost of carrying out the works. Who bears the cost of this? It falls on the contractor initially, as it is the party that will sustain any additional cost. The contractor may recover some or all of these increased costs if the contract provides that adverse weather is a compensatory event. In that situation the weather risk is being allocated to the employer.

Under JCT the only risk allocated to the employer for adverse weather is the time consequences. This is illustrated by the fact that the contractor will be entitled to an extension of time, and so relief from liquidated damages for the period of delay caused by the adverse weather. It will not be entitled to an increase in the contract price for this. The position is different under certain other standard forms.

But what about those risks that are not expressly allocated? [鈥�] Where the contract is silent on who bears the risk of particular events, can this be deduced from the other provisions within the contract?

Another commonly encountered risk is that of unforeseen ground conditions. If the contract is silent on these (and dealing with them does not fall within the definition of a variation to the works), the costs of them being encountered and therefore the risk will lie with the party that has to deal with them, namely the contractor.

Uncertainty as to who bears which risks is presumably why NEC3, in clauses 80 and 81 鈥� entitled 鈥渃ontractor鈥檚 risks鈥� 鈥� took a different approach to that of other standard forms. It lists the risks that lie with the employer, including any stated to be so in the contract data, and then concludes with the contractor bearing all other risks: 鈥淔rom the starting date until the defects certificate has been issued, the risks which are not carried by the employer are carried by the contractor.鈥�

When the defects certificate is issued and the employer has taken over, this approach is reversed: the employer bears the risk of loss or damage except for that due to defects existing at takeover.

NEC does not exclude insured risks from the risk allocation. To the extent that an insurance policy does not cover the costs, that will be dealt with in accordance with the contract risk allocation (see: SSE vs Hochtief [2015] CSOH 92).

This NEC approach to risk allocation has not removed all uncertainty. A party must still identify which risks are carried by the employer before knowing what risks are left with the contractor. But where do you look to identify the risks allocated to the employer? Is it only in the contract conditions? What about other contract documents?

The new FIDIC forms due next month have adopted and developed the same approach. They have a new clause 17, entitled 鈥渞isk allocation鈥�. This clause states that risks allocated to the employer are divided into commercial risks and property/works damage risks, both of which are defined. Then there is a 鈥渟weep up鈥� under clause 17.2, which states that 鈥渢he risks allocated to the contractor and for which the contractor is liable are all the risks other than those listed as employer鈥檚 risks鈥�.

But just as FIDIC moves towards NEC3 on this, NEC4 has changed its mind. It has abandoned the 鈥渁ll other risks lie with the contractor鈥� approach. Instead, it lists each of the contractor鈥檚 risks in the same way it does the employer鈥檚. It has also removed all references to 鈥渞isk鈥� and replaced them with the term 鈥渓iability鈥�. Have we come full circle? Do we have to accept that the contract will never be able to deal specifically with all risks?

Where the contract does not allocate a risk expressly or by implication, the cost consequences will need to be borne by the party that has to deal with it.

Lindy Patterson QC is arbitrator and adjudicator at 39 Essex Chambers